(954)8002840

Terms & Condition

Last Updated: November 1, 2025
Company Name: West Sky Roofing
Address: 922 Belvedere Rd, West Palm Beach, FL 33405, USA
Email: info@westskyroofing.com
Phone: (954) 800-2840

1. Introduction

Welcome to West Sky Roofing.
These Terms and Conditions (“Terms”) govern your use of our website, services, and communications.
By accessing our website or using our services, you agree to be bound by these Terms. If you do not agree, please discontinue use of our website and services.

2. Services Provided

West Sky Roofing provides professional roofing services including:

  • Roof Installation

  • Roof Repair

  • Roof Replacement

  • Commercial Roofing

  • Roof Maintenance

  • Emergency Roof Repair

All services are performed by trained and licensed professionals according to Florida building codes and safety standards.

Service availability may vary by location, weather conditions, and scheduling.

3. Estimates and Quotes

All quotes and estimates provided by West Sky Roofing are free and non-binding unless otherwise specified.
Estimates are based on the information available at the time of inspection.
Prices are subject to change if additional work, materials, or unforeseen damage is discovered once the project begins.

We will always notify you and obtain approval before proceeding with any additional work beyond the original estimate.

4. Payments and Billing

Payment terms will be outlined in your project proposal or invoice.
Unless otherwise agreed in writing, payment is due as follows:

  • A deposit may be required before work begins.

  • The remaining balance is due upon completion of the project.

We accept payments by cash, check, or approved electronic methods.
Late payments may be subject to interest fees or collection actions.

West Sky Roofing reserves the right to pause or terminate work if payments are not received according to agreed terms.

5. Scheduling and Project Completion

We make every effort to complete projects within the estimated timeframe; however, timelines may change due to:

  • Weather delays

  • Material availability

  • Changes requested by the client

  • Unforeseen structural conditions

We are not responsible for delays caused by circumstances beyond our control.
In all cases, we will communicate updates and revised schedules promptly.

6. Warranties and Guarantees

West Sky Roofing stands behind the quality of our workmanship.
All roofing projects include applicable warranties based on materials and service type, which will be specified in your written contract.

Warranty coverage does not apply to:

  • Damage caused by severe weather (hurricanes, hail, storms, etc.)

  • Improper maintenance, neglect, or third-party modifications

  • Natural wear and tear over time

To maintain warranty validity, roofs should be inspected and maintained as recommended.

7. Customer Responsibilities

As a client, you agree to:

  • Provide accurate information about your property and roofing needs.

  • Allow access to the work area during agreed hours.

  • Ensure safety and clearance of personal belongings, pets, and vehicles near the worksite.

  • Comply with payment schedules and signed agreements.

Failure to provide access or payment may result in project delays or termination of services.

8. Limitation of Liability

To the fullest extent permitted by law, West Sky Roofing and its affiliates are not liable for:

  • Indirect, incidental, or consequential damages (e.g., loss of property value, business interruption, emotional distress).

  • Damage resulting from existing structural defects or pre-existing conditions.

  • Delays caused by weather, supply shortages, or third-party factors.

Our total liability shall not exceed the total amount paid by you for the roofing services in question.

9. Intellectual Property

All content on this website — including text, images, logos, graphics, and design — is the property of West Sky Roofing or its licensors and protected under copyright law.

You may not copy, reproduce, modify, distribute, or use any content from our website for commercial purposes without written consent.

10. Website Use

By using our website, you agree to:

  • Use it only for lawful purposes.

  • Refrain from uploading or sharing malicious content.

  • Not engage in data scraping, spam, or unauthorized advertising.

We reserve the right to restrict access, remove content, or block users who violate these Terms.

11. Third-Party Links

Our website may contain links to third-party websites for your convenience.
These links do not imply endorsement.
West Sky Roofing is not responsible for the content, accuracy, or privacy practices of any linked external websites.

12. Termination of Services

We reserve the right to refuse, suspend, or terminate services at our discretion if:

  • The client breaches these Terms or the signed contract.

  • Unsafe or hazardous conditions exist on the property.

  • Payment terms are violated.

In such cases, all outstanding balances must be paid in full for work completed to date.

13. Indemnification

You agree to indemnify and hold West Sky Roofing, its employees, contractors, and affiliates harmless from any claims, damages, or expenses (including legal fees) arising from your breach of these Terms, misuse of our website, or negligence related to our services.

14. Governing Law

These Terms and Conditions are governed by the laws of the State of Florida.
Any disputes shall be resolved in the courts located in Palm Beach County, Florida.

15. Changes to These Terms

We may update or modify these Terms at any time without prior notice.
Changes will take effect immediately upon posting to our website.
By continuing to use our website or services after updates, you accept the revised Terms.

16. Contact Us

If you have any questions or concerns about these Terms and Conditions, please contact us:

West Sky Roofing
📍 922 Belvedere Rd, West Palm Beach, FL 33405, USA
📧 info@westskyroofing.com
📞 (954) 800-2840